These Terms govern your use of our website and our interior design services in Australia. By engaging Dune Harbor, you agree to these Terms.
“We”, “us”, and “our” refer to Dune Harbor. “You” and “Client” refer to the person or entity engaging our services. “Project” refers to the scope described in our proposal or statement of work.
We provide interior and architectural design, documentation, selections, procurement support, and site coordination as agreed in writing. Services outside the agreed scope may be treated as variations.
We issue proposals or quotes after understanding your brief. Payment schedules and milestones are set out in the proposal. Any statutory taxes and third-party costs are payable by the Client unless otherwise stated.
Invoices are due according to the terms on the invoice. Late payment may pause services until payment is received.
Design is iterative; however, changes after approval or beyond the included revision rounds may incur additional fees. If you cancel a Project, you agree to pay for work completed to date and any committed third-party costs.
We retain ownership of all design concepts, drawings, specifications, text, and imagery we create, except to the extent third-party rights apply. Upon full payment, you receive a non-exclusive licence to use deliverables for the Project site only. Reuse on other sites or projects requires our written consent.
You grant us permission to photograph completed works and reference the Project in our portfolio, website, and media, provided we do not disclose confidential information. If you wish to restrict publicity, notify us in writing before completion.
We may recommend suppliers or contractors. Recommendations are provided in good faith; you remain responsible for entering contracts and verifying warranties with third parties.
To the extent permitted by law, we exclude implied warranties and limit our liability to re-supplying services or paying the cost of re-supply. We are not liable for indirect or consequential loss, delays caused by third parties, or matters outside our reasonable control.
Timeframes are estimates and depend on approvals, contractor availability, and material lead times. We will communicate updates and seek to minimise delays.
Your information is handled in line with our Privacy Policy. Our use of cookies is described in our Cookie Policy, and you can manage preferences via the cookie banner.
These Terms are governed by the laws of South Australia and the Commonwealth of Australia. The parties submit to the non-exclusive jurisdiction of the courts of South Australia.
If a dispute arises, the parties will first attempt to resolve it in good faith through discussion. If unresolved after 30 days, either party may seek mediation before commencing legal proceedings, except for urgent injunctive relief.
Questions about these Terms can be directed to: